ADVERTISEMENT FOR PREQUALIFICATION AND BIDS PREQUALIFICATION PROPOSALS will be received via email, or other electronic transmission, and one paper copy, on behalf of the Owner by Goodwyn, Mills & Cawood, Inc., at 7 Town Center Dr., Ste. 201, Huntsville, AL 35806, for the below referenced project, until 2:00 PM Local Time, Wednesday, September 2, 2015. The prequalification procedure is intended to identify responsible and competent bidders relative to the requirements of the Project. Prequalification proposal requirements may be obtained from the Architect, by request either by phone (256.539.3431) or e-mail leah.swinney@gmcnetwork.com, to Leah Swinney. Additional qualifications and requirements for General Contractor Bidders and separate Subcontractors are indicated in the Bid and Contract Documents. SEALED PROPOSALS will be received only from previously PRE-QUALIFIED General Contractors by the Limestone County Schools, located at 300 South Jefferson Street, Athens, Alabama, 35611; until 2:00 PM Local Time, Tuesday, September 22, 2015, for this project: ADDITIONS TO CREEKSIDE ELEMENTARY SCHOOL Harvest, Alabama for the LIMESTONE COUNTY SCHOOLS (LOCALLY FUNDED) at which time and place they will be publicly opened and read. A cashiers check or bid bond payable to LIMESTONE COUNTY SCHOOLS in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and statutory Labor and Material Payment Bonds, and insurance in compliance with requirements, will be required at the signing of the Contract. Drawings and Specifications may be examined at the Office of the Architect; Bid Clerk; Dodge Data & Analytics; CMD Group; Data Fax; and iSqFt Plan Room. Bid documents (Plans, Specifications and Addenda) will be sent to prequalified General Contractors only from the Architect electronically with no deposit. Partial sets will not be available. General Contractors should contact Leah Swinney via phone (256.539.3431) or e-mail leah.swinney@gmcnetwork.com to request electronic documents. Subcontractors should contact a General Contractor or plan room for documents. Only General Contractors who have completed the prequalification process within the stated time limits, and which are properly licensed in accordance with criteria established by the State Licensing Board for General Contractors under the Provision of Title 34, Chapter 8, Code of Alabama, 1975, as amended, will be considered for prequalification for the Work of this project. A MANDATORY PRE-BID CONFERENCE will be held at the same location as bids are to be opened, at 2:00 PM local time Thursday, September 10, 2015, for the purpose of reviewing the project and answering Bidders questions. Attendance at the Pre-Bid Conference IS REQUIRED for all General Contractor Bidders intending to submit a Proposal, and is highly recommended for Subcontractors. Bids from General Contractors not attending the Pre-Bid Conference will be rejected. Any and all plan holders intending to submit a bid on the project referenced above must submit a written registration with the Architect prior to bid. There are no exceptions. Bidder Registrations may be emailed or faxed to: Goodwyn Mills and Cawood, attention: Leah Swinney. Email: leah.swinney@gmcnetwork.com or Fax: (256)536-9913. Bids will not be accepted from unregistered bidders. It is the sole responsibility of the Bidder to confirm with the Office of the Architect receipt of registration. Per the Owner and the Alabama Department of Revenue (ADOR), Act 2013-205, the project will be bid EXCLUDING TAXES and will require the Contractor to complete ABC Form C-3A Accounting of Sales Tax Attachment to ABC Form C-3 Proposal Form (October 2013) which will be submitted with the Contractors Proposal at the time of the Bid. If awarded the bid, both tax exempt entity and contractor shall apply for certificates of exemption. ADOR shall issue certificates of exemption from sales and use tax for each tax exempt project. Certificates shall only be issued to contractors licensed by the State Licensing Board for General Contractors or any subcontractor working under the same contract. Items eligible for exemption are building materials, construction material and supplies and other tangibles that become part of the structure. ADOR will handle the administration of the certificates and the accounting of exempt purchases. The owner reserves the right to reject any or all proposals, to waive technical errors and/or abandon the prequalification and bid process if, in their judgment, the best interests of the Owner will thereby be promoted. Limestone County Schools 300 S. Jefferson St. Athens, AL 35611 Goodwyn, Mills & Cawood, Inc. Members, American Institute of Architects 7 Town Center Dr., Suite 201 Huntsville, AL 35806 PH: 256-539-3431 Fax: 256-536-9913 The News Courier August 21, 28 and 30, 2015
↧